Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion
April 15, 2024 —
Stu Richeson - The Dispute ResolverThis post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded.
Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009).
Read the full story...Reprinted courtesy of
Stu Richeson, PhelpsMr. Richeson may be contacted at
stuart.richeson@phelps.com
Finding an "Occurrence," Appellate Court Rules Insurer Must Defend
March 11, 2024 —
Tred R. Eyerly - Insurance Law HawaiiReversing the trial court, the Wisconsin Court of Appeals found the insurer must defend a cross-claim against the insured owner of a building after an explosion occurred. LBC, LLC v Spectrum Brands, Inc., 2023 Wis. App. LEXIS 1251 (Wis. Ct. App, Nov. 30, 2023).
LBC leased commercial property to Spectrum. Spectrum stored lithium on the property. The lithium exploded when it came into contact with water that entered the premises during historic flooding in August 2018. Spectrum remediated the premises, vacated the premises prior to the lease's termination date, and stopped paying rent.
LBC sued Spectrum, alleging that Spectrum negligently stored the lithium and that Spectrum breached the lease. Spectrum counterclaimed, alleging that LCB breached the lease in various respects, that LCB negligent allowed water to infiltrate the premises, and that Spectrum was constructively evicted. LCB tendered the counterclaim to its insurer, General Casualty. The tender was denied and LCB sued.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
More In-Depth Details on the Davis-Bacon Act Overhaul
November 06, 2023 —
Seth C. Wiseman & Angela M. Richie - Construction ExecutiveThe U.S. Department of Labor’s finalization of a
rule updating the Davis-Bacon Act, the federal law that governs how prevailing wages for federal construction projects can be determined, will have a significant impact on contractors and workers alike in the construction industry. The new rule, in effect, adopts the 30% rule, meaning that the prevailing wages must be equal to the wage paid to at least 30% of workers of a particular classification in a particular area. The new rule also implements a new anti-retaliation provision, specifically protecting construction workers who raise concerns about payment practices from adverse employment actions. The timing of this new rule is particularly significant for contractors, as it will likely raise the cost of labor for contractors at a time when the Infrastructure Investment and Jobs Act and the CHIPS Act are providing additional funding for federal projects across the country. Thus, it is important for all parties in the construction industry to understand the updated rule in order to evaluate the short-term impacts on their respective projects and long-term impact on their respective businesses.
Reprinted courtesy of
Seth C. Wiseman & Angela M. Richie, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Mr. Wiseman may be contacted at swiseman@grsm.com
Ms. Richie may be contacted at arichie@grsm.com
Read the full story...
Spencer Mayer Receives Miami-Dade Bar Association's '40 Under 40' Award
March 04, 2024 —
Lewis Brisbois NewsroomMiami, Fla. (February 23, 2024) – Miami Associate Spencer Mayer received the 2024 Miami-Dade Bar Association Young Lawyers Section’s '40 under 40' Award at the association's annual "Miami Nights" event on February 22.
Mr. Mayer serves on the Board of Directors of the Miami Dade Bar Association’s Young Lawyers Section. Lewis Brisbois was a proud sponsor of this event, which raised funds for the organization's community service initiatives and pro bono programming.
Mr. Mayer is a member of the General Liability Practice. His practice focuses on all aspects of civil litigation, including complex commercial litigation, products liability, premises liability, wrongful death, catastrophic injury, and insurance coverage.
Read the full story...Reprinted courtesy of
Lewis Brisbois
Quick Note: October 1, 2023 Changes to Florida’s Construction Statutes
November 13, 2023 —
David Adelstein - Florida Construction Legal UpdatesEffective October 1, 2023, there were changes to Florida’s statutory scheme dealing with construction projects. This includes Florida’s Lien Law. A copy of these changes can be found below which identify additions in blue and deletions with strikethroughs. No different than before, if you have questions or concerns as to your statutory rights on a construction project, do the prudent thing, consult a construction lawyer. A construction lawyer can help you understand changes to the applicable statutory scheme or how the statutory scheme pertains to your rights. This is important because you want to make sure you understand statutory changes that apply to your work and rights.
A noteworthy change, bolded in blue below, is that there is now a basis to lien for a contractor performing construction management services “which include scheduling and coordinating construction and preconstruction phases for the construction project, or who provides program management services”:
Fla. Stat. s. 713.01 (8) “Contractor” means a person other than a materialman or laborer who enters into a contract with the owner of real property for improving it, or who takes over from a contractor as so defined the entire remaining work under such contract. The term “contractor” includes an architect, landscape architect, or engineer who improves real property pursuant to a design- build contract authorized by s. 489.103(16). The term also includes a licensed general contractor or building contractor, as those terms are defined in s. 489.105(3)(a) and (b), respectively, who provides construction management services, which include scheduling and coordinating preconstruction and construction phases for the construction project, or who provides program management services, which include schedule control, cost control, and coordinating the provision or procurement of planning, design, and construction for the construction project.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Action Needed: HB24-1230 Spells Trouble for Colorado Construction Industry and its Insurers
March 25, 2024 —
David McLain - Higgins, Hopkins, McLain & Roswell, LLCIn an apparent gift to plaintiffs’ construction defect lawyers, Representatives Parenti and Bacon introduced House Bill 24-1230 on February 12, 2024. The bill was assigned to the House Judiciary Committee and is scheduled for hearing on March 6th, during the afternoon session beginning at 1:30 pm. To date, the bill does not have any senate sponsors, perhaps because the senators are more interested in serving their constituents’ needs for attainable housing than in lining the pockets of their plaintiffs’ construction defect attorney friends.
According to the bill’s summary, HB 24-1230 contains the following provisions:
Current law declares void any express waivers of or limitations on the legal rights or remedies provided by the “Construction Defect Action Reform Act” or the “Colorado Consumer Protection Act.” Sections 1 and 4 make it a violation of the “Colorado Consumer Protection Act” to obtain or attempt to obtain a waiver or limitation that violates the aforementioned current law.
Read the full story...Reprinted courtesy of
David McLain, Higgins, Hopkins, McLain & RoswellMr. McLain may be contacted at
mclain@hhmrlaw.com
AAA Revises its Construction Industry Arbitration Rules and Mediation Procedures
April 02, 2024 —
Garret Murai - California Construction Law BlogThis one is for the lawyers. Or for those of you who are claims-minded . . .
Effective March 1, 2024, the American Arbitration Association (“AAA”) revised its Construction Industry Arbitration Rules and Mediation Procedures. For those involved in construction, this is important since the AAA Rules are the default arbitration rules contained in AIA form contracts and are often the arbitration rules referenced in other construction contracts as well.
So, what are the changes?
- General: Fax numbers have gone the way of the Dodo bird and replaced by email addresses for all parties. Also, while already done in practice, preliminary hearings may now be held via videoconference in addition to telephone and in-person (Rule R-23).
Read the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
It Pays to Review the ‘Review the Contract Documents’ Clause Before You Sign the Contract
March 11, 2024 —
Alan Winkler - ConsensusDocsIt is fairly common for a construction contract to include a provision requiring the contractor to perform some level of review of the plans and specifications and perhaps other contract documents as part of their responsibilities. Typically, this provision is found in a section of the contract on the contractor’s responsibilities, although it can be anywhere. Owners and contractors are, with reason, focused on three main issues in reviewing contracts: (1) price, costs, and payments, (2) time and scheduling, and (3) scope of the work. Eyes may glaze over the contractor’s responsibilities section. Not only does it seem to be boilerplate, but industry professionals know what a contractor is supposed to do; in a nutshell, build the project.
An old school type of contractor may regard this role as strictly following the plans and specifications, no matter what they provide. That could lead to a situation where construction comes to a complete stop because, for example, two elements are totally incompatible with each other. If that happens, the contractor would then turn to the owner and architect to ask for a corrective plan and instructions on how to proceed. That may also be accompanied by a request for more time and money while the problem is resolved. The ‘review the contract documents’ clause is designed to avoid this. It is intended to address an understanding that everyone makes mistakes, even architects and engineers whose job it is to design a buildable, functional project. The clause also addresses the understanding that a contractor is more than a rote implementer of plans and specifications because its expertise in building necessarily means the contractor has expertise in understanding the documents that define the construction and how things are put together.
Read the full story...Reprinted courtesy of
Alan Winkler, Peckar & Abramson, P.C.Mr. Winkler may be contacted at
awinkler@pecklaw.com