Ruling Dealing with Constructive Changes, Constructive Suspension, and the Implied Covenant of Good Faith and Fair Dealing
January 22, 2024 —
David Adelstein - Florida Construction Legal UpdatesA dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt.
The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
It Pays to Review the ‘Review the Contract Documents’ Clause Before You Sign the Contract
March 11, 2024 —
Alan Winkler - ConsensusDocsIt is fairly common for a construction contract to include a provision requiring the contractor to perform some level of review of the plans and specifications and perhaps other contract documents as part of their responsibilities. Typically, this provision is found in a section of the contract on the contractor’s responsibilities, although it can be anywhere. Owners and contractors are, with reason, focused on three main issues in reviewing contracts: (1) price, costs, and payments, (2) time and scheduling, and (3) scope of the work. Eyes may glaze over the contractor’s responsibilities section. Not only does it seem to be boilerplate, but industry professionals know what a contractor is supposed to do; in a nutshell, build the project.
An old school type of contractor may regard this role as strictly following the plans and specifications, no matter what they provide. That could lead to a situation where construction comes to a complete stop because, for example, two elements are totally incompatible with each other. If that happens, the contractor would then turn to the owner and architect to ask for a corrective plan and instructions on how to proceed. That may also be accompanied by a request for more time and money while the problem is resolved. The ‘review the contract documents’ clause is designed to avoid this. It is intended to address an understanding that everyone makes mistakes, even architects and engineers whose job it is to design a buildable, functional project. The clause also addresses the understanding that a contractor is more than a rote implementer of plans and specifications because its expertise in building necessarily means the contractor has expertise in understanding the documents that define the construction and how things are put together.
Read the full story...Reprinted courtesy of
Alan Winkler, Peckar & Abramson, P.C.Mr. Winkler may be contacted at
awinkler@pecklaw.com
Best Practices: Commercial Lockouts in Arizona
March 19, 2024 —
Patrick Tighe - Snell & Wilmer Real Estate Litigation BlogIf a tenant defaults under a commercial lease, Arizona law permits the landlord to re-take possession of the premises by locking out the defaulting tenant. However, if the landlord’s lockout is wrongful, the landlord may be liable for the damages the tenant sustains because of the wrongful lockout. To minimize such liability, here are some general best practices to follow when locking out a defaulting tenant:
- Do Not Breach the Peace. It is vital when performing a lockout to not breach the peace. What constitutes a “breach of the peace” depends on the particular circumstances at hand. For example, if a tenant arrives during the lockout and becomes angry or threatens violence, the landlord should stop performing the lockout and return at a later time. As a general rule of thumb, it is best to perform lockouts in the early morning hours or in the late evening hours when the landlord is less likely to encounter the tenant.
- Provide A Notice of Default. Many commercial leases require the landlord to provide a notice of default before the landlord can lock out a defaulting tenant. Check, double check, and triple check that the landlord followed the lease’s notice of default provisions correctly, including that the landlord sent the notices to all required parties in accordance with the time requirements set forth in the lease.
Read the full story...Reprinted courtesy of
Patrick Tighe, Snell & WilmerMr. Tighe may be contacted at
ptighe@swlaw.com
Antidiscrimination Clause Required in Public Works and Goods and Services Contracts –Effective January 1, 2024
January 22, 2024 —
Travis Colburn - Ahlers Cressman & SleightIn July 2023, the Washington legislature passed Senate Bill 5186, which mandates inclusion of select antidiscrimination clauses in every state contract and subcontract for public works, goods, or services executed after January 1, 2024.
[i] RCW 49.60.530(3) codifies the now-required antidiscrimination clauses, which prohibit four categories of discrimination against any person because of age, sex, marital status, sexual orientation, gender identity, race, creed, color, national origin, citizenship or immigration status, honorably discharged veteran or military status, the presence of any sensory, mental, or physical disability, or the use of a trained dog guide or service animal by a person with a disability (the “Protected Class”).
Under the new law, public contractors and subcontractors (“Public Contractor”) may not refuse to hire a person because that person is a member of the Protected Class, unless that refusal is based upon a bona fide occupational qualification or if a person with a particular disability would be prevented from properly performing the particular work involved.
[ii] Similarly, Public Contractors may not discharge or bar a person from employment or discriminate against any person – either in terms of compensation or other terms and conditions of employment – because that person is a member of the Protected Class.
[iii] Last, Public Contractors may not print or circulate (or cause to be printed or circulated) any statement, advertisement, publication, form of application for employment, or make inquiry in connection with prospective employment, which expresses any limitation, specification, or discrimination as to the Protected Class.
[iv] Read the full story...Reprinted courtesy of
Travis Colburn, Ahlers Cressman & SleightMr. Colburn may be contacted at
travis.colburn@acslawyers.com
Federal Magistrate Judge Recommends Rescission of Policies
February 12, 2024 —
Craig Rokuson - Traub LiebermanIn the recent case of Union Mut. Fire Ins. Co. v. 142 Driggs LLC, 2023 U.S. Dist. LEXIS 220393, Magistrate Judge Lois Bloom of the United States District Court for the Eastern District of New York recommended granting the insurer's default judgment and holding that of three policies issued to 142 Driggs LLC ("Driggs") be rescinded ab initio.
Driggs had represented on its insurance applications that it did not provide parking to anyone other than itself, tenants, and its guests at the subject insured premises. However, Union Mutual learned that Driggs had been renting out three garages to non-tenants. Second, Driggs represented that the mercantile square footage was around 1,000 square feet, when in actuality, it was larger than allowed under the policies.
Union Mutual provided underwriting guidelines in connection with its default motion, which state that "parking provided for anyone other than the insured, tenants and their guests," presents an "unacceptable risk." The guidelines also state that answering yes to any "preliminary application questions (which presumably included those regarding mercantile square footage and parking) is an "unacceptable risk." The court held that these guidelines supported a finding that Driggs made material misrepresentation and that Union Mutual relied on these misrepresentations in issuing the policies. The court, as such, recommended that the policies at issue be rescinded from inception.
Read the full story...Reprinted courtesy of
Craig Rokuson, Traub LiebermanMr. Rokuson may be contacted at
crokuson@tlsslaw.com
Partner John Toohey and Senior Associate Sammy Daboussi Obtain a Complete Defense Verdict for Their Contractor Client!
December 11, 2023 —
Bremer Whyte Brown & O'Meara LLPBremer Whyte Brown & O’Meara, LLP is excited to share that Newport Beach attorneys John Toohey and Sammy Daboussi obtained a complete defense verdict after years-long litigation in favor of their concrete contractor client.
This lawsuit arises from a claim made by Plaintiff for construction defects in a high-end single-family home. Our client was hired to perform concrete work on the foundations of the home. It was alleged that the home’s foundation was incorrectly built. It was further alleged that the construction defects/errors led to delays and substantial expenses. We argued that our client relied on the certifications provided to them by design professionals and the City. We further argued that our client, like any reasonable concrete/foundation subcontractor, has no responsibility or obligation, contractual or otherwise, to review and recheck the work completed by a licensed professional.
Read the full story...Reprinted courtesy of
Bremer Whyte Brown & O'Meara LLP
Appellate Court of Maryland Construes Notice Conditions of A312 Performance Bond in Favor of Surety
January 02, 2024 —
Joel P. Williams - White and Williams LLPThe Appellate Court of Maryland issued a reported opinion in a case construing an American Institute of Architects (“AIA”) A312 performance bond. In Wildewood Operating Company, LLC v. WRV Holdings, LLC, et al. 2023 Md. App. LEXIS 720 (Oct. 30, 2023), the Appellate Court of Maryland held that a performance bond surety was discharged from liability where the owner/obligee failed to give the surety notice of the contractor’s default termination until after a third party had completed the work.
The project concerned the construction of an assisted living facility in St. Mary’s County, Maryland. The owner, Wildewood Operating Company, LLC, entered into an A312-2010 performance bond with Clark Turner Construction, LLC, as contractor, and First Indemnity of America Insurance Company, as surety. When Clark Turner failed to complete certain stormwater management work adjacent to the site, Wildewood, Clark Turner, and other parties entered into a Work Agreement to address completion of the work. The surety was not a party to the Work Agreement.
Read the full story...Reprinted courtesy of
Joel P. Williams, White and Williams LLPMr. Williams may be contacted at
williamsj@whiteandwilliams.com
Real Estate & Construction News Roundup (4/17/24) – Travel & Tourism Reach All-Time High, President Biden Emphasizes Housing in SOTU Address, and State Transportation Projects Under Scrutiny
May 13, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, Airbnb advocates for new short-term rental rules, the U.S. Supreme Court rules on hefty development fees, loan losses becomes a greater issue for banks, and more!
Read the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team