Anaheim California Construction Expert Witness Directory

Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion

April 15, 2024 — Stu Richeson - The Dispute Resolver
This post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded. Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009). Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

The Top 3 Trends That Will Impact the Construction Industry in 2024

December 04, 2023 — The Hartford Staff - The Hartford Insights
As more than 40% of the current U.S. construction workforce will retire in the next decade, industry leaders need to equip themselves with the necessary resources to combat the shifting work environment.1 “Trends in the construction industry will fluctuate in the coming years, which can lead to additional risks for industry leaders. It will be important to think about how they can address any potential risk factors. A lot of leaders have been increasing their planning efforts and looking into technology solutions to combat the ongoing labor shortage,” said David DeSilva, head of construction at The Hartford. Here, he outlines the top three top trends for business leaders to watch in 2024. 1. Ongoing Labor Shortages Construction is an industry that traditionally has a high labor turnover rate, which means companies needs to hire more frequently. This only increases during labor shortages. The construction workforce is up against several factors, including an aging workforce and recruitment struggles. Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

Washington’s Court of Appeals Protects Contracting Parties’ Rights to Define the Terms of their Indemnity Agreements

March 19, 2024 — Margarita Kutsin - Ahlers Cressman & Sleight PLLC
It has long been the law in Washington that contracting parties are free to draft contractual indemnity agreements to allocate risk arising from performance of the work, and Courts will generally enforce those agreements as written. This well-settled principle was recently reaffirmed in King County v. CPM Development Corp., dba ICON Materials[1] a decision from Division I of the Washington Court of Appeals, wherein one party to an indemnity agreement attempted to evade its contractual obligations by arguing that certain common law indemnity principles supersede the written terms. This appeal followed a multi-week jury trial from which the client and Ahlers Cressman and Sleight legal team, including Lindsay Watkins, Klien Hilliard, and Christina Granquist, obtained a seven-figure judgment in the client’s favor, including an award of all attorneys’ fees and costs. ICON was the general contractor on a Vashon Island Highway Pavement project for King County. Part of the work on the project involved hauling away and disposing of ground milled asphalt (the “millings”) at King County-approved sites. ICON and D&R Excavating Inc., (“D&R”) executed a subcontract for D&R to perform that work. The subcontract incorporated the contract between ICON and King County, including the obligation to stockpile millings only at approved sites. D&R, however, did not obtain the requisite approvals from King County, and placed the millings at various sites on the Island, including locations that King County explicitly rejected. Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight PLLC
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Real Estate & Construction News Roundup (1/16/24) – Algorithms Affect the Rental Market, Robots Aim to Lower Construction Costs, and Gen Z Struggle to Find Their Own Space

February 12, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, New York’s Prompt Payment Act comes into question, vacancy rates rise in commercial office space, the Biden administration applies project labor agreements on certain federal construction projects, and more!

The Biden administration announced the implementing on an executive order that will require project labor agreements on federal construction projects costing $35 million or more, likely resulting in PLAs being required on a majority of large federal jobs. (Zachary Phillips, Construction Dive)
Boeing plans to increase quality inspections of its 737 Max 9 aircraft, following a series of manufacturing flaws that have led some airlines to hold off aircraft purchases or go with its European rival, Airbus. (Ken Sweet, AP)
31% of Generation Z (generally defined as those born between 1996 and 2012) adults live at home with parents because they can’t afford to buy or rent their own space. (Jessica Dickler, CNBC)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Real Estate & Construction News Roundup (09/12/23) – Airbnb’s Future in New York City, MGM Resorts Suffer Cybersecurity Incident, and Insurance Costs Hitting Commercial Real Estate

October 30, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, the FDIC handles the portfolio from Signature Bank, the U.S. Army Corps of Engineers funds a new center at Illinois, the Athletics take their next steps in their move to Las Vegas, and more!

For those looking to rent an Airbnb for future travel to New York City, it just became much harder with new rules taking effect on September 5th. (Natalie Lung, The Washington Post)
This past weekend MGM Resorts suffered a cybersecurity incident that affected some of the company’s systems with the extent of the incident still unknown. (ABC)
Among issues such as rent increases and general inflation, commercial real estate is also having to contend with rising insurance costs due to climate change. (Justin Worland, Time)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Top 10 Insurance Cases of 2023

January 29, 2024 — Jeffrey J. Vita & Michael A. Amato - Saxe Doernberger & Vita, P.C.
Federal and state courts tackled many interesting insurance-related issues this past year. Perhaps no state had a more impactful year than Illinois, which held that construction defects could constitute an occurrence, that a LEG 3 “extension” attempting to preclude coverage for faulty or defective workmanship was ambiguous as a matter of law (applying Illinois law), and that ostensibly prohibitive “catch-all exclusions” can render policy language ambiguous in favor of coverage. Other courts wrestled with procedural inquiries, such as the legal duty of a broker in providing notice to an insurer or the ability of an insured to recoup its attorneys’ fees in pursuing a coverage action against its insurer. These are merely a sampling of the impactful insurance decisions rendered in 2023. Each year, we endeavor to identify cases of general interest to our clients and the broader insurance community. Specifically, we attempt to identify trends, cases of first impression, cases illustrating conflicts among the courts, or cases dealing with emerging issues. We now proudly unveil the top 10 most influential coverage decisions of 2023 and look ahead to a few cases to watch as 2024 unfolds. Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita, P.C. and Michael A. Amato, Saxe Doernberger & Vita, P.C. Mr. Vita may be contacted at JVita@sdvlaw.com Mr. Amato may be contacted at MAmato@sdvlaw.com Read the full story...

Haight Celebrates 2024 New Partner Promotions!

January 22, 2024 — Haight Brown & Bonesteel LLP
Haight is celebrating new partner promotions in 2024. Congratulations to Gary LaHendro, Melvin Marcia and Philip McDermott! Gary LaHendro became a member of the California State Bar in December 1993. He is a member of the Risk Management & Insurance Law Practice Group. He focuses his practice on insurance coverage and bad faith litigation. Gary’s clients include carriers within the United States and London Markets for whom he has provided coverage advice on various lines of coverage, including commercial general liability, excess, errors and omissions, auto, and representations and warranties. Gary also monitors the defense of insureds with respect to third-party lawsuits. In addition to coverage work, Gary has over 20 years of litigation experience as lead defense counsel on cases involving soil and groundwater contamination, professional liability, construction defect and personal injury cases. He is also a skilled appellate attorney and Certified Mediator. Melvin Marcia became a member of the California State Bar on June 1, 2016. Melvin is a member of the firm’s Transportation Law, General Liability, Product Liability and Fire Litigation Practice Groups. His practice focuses on litigation of high value cases, ranging from catastrophic injury, wrongful death, premises liability, business disputes, product liability, uninsured/underinsured arbitrations and subrogation matters. Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

More Clear, But Not Yet Crystal: Virginia Amends its Prompt Payment Law and Legislation Banning “Pay-If-Paid Clauses in Construction Contracts Effective July 1, 2023

November 16, 2023 — Hanna Lee Blake - ConsensusDocs
The Virginia General Assembly has joined a minority of jurisdictions that ban pay-if-paid clauses in construction contracts on public and private projects. Senate Bill 550 went into effect applying to contracts executed after January 1, 2023, and most recently has been amended effective July 1, 2023. This update highlights the recent amendments to Virginia’s prohibition against pay-if-paid provisions, of which owners and contractors should be aware to ensure that their contracts comply with developing law in the Commonwealth. Recap on Senate Bill 550 On April 27, 2022, the Virginia General Assembly passed Senate Bill 550, which amended Virginia Code §§ 2.2-4354 and 11-4.6, which govern both public and private sector contracts. In short, SB 550 (as the bill is commonly known) prohibited pay-if-paid clauses, and established fixed deadlines for the payment of invoices on private projects. Previously, Virginia’s Prompt Payment Act only applied to public projects. Read the full story...
Reprinted courtesy of Hanna Lee Blake, Watt Tieder
Ms. Blake may be contacted at hblake@watttieder.com

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES