When is a Construction Project truly “Complete”? That depends. (law note)
August 2, 2012 — Melissa Dewey Brumback, Construction Law North Carolina
Long-time readers of the blog may remember my earlier post on substantial completion. However, in looking over my blog stats to see what search terms lead people here, it looks like this is hot topic. The blog searches came in two general categories:
1. Those searching strictly for a definition of substantial completion. Some examples:
- What does “substantial completion” mean?
- when does a building achieve substantial completion
- contracts “substantial completion”
- substantial completion undefined
- when is a project substantially complete
Read the full story…
Reprinted courtesy of Melissa Dewey Brumback of Ragsdale Liggett PLLC. Ms. Brumback can be contacted at mbrumback@rl-law.com.
Texas contractual liability exclusion
May 18, 2011 — May 18, 2011 - CDCoverage.com
In Ewing Construction Co., Inc. v. Amerisure Ins. Co., No. C-10-256 (S.D. Tex. April 28, 2011), insured Ewing was the general contractor for an athletic facility constructed for a school district. The school district sued Ewing alleging defective construction of the project. The underlying complaint included contract and negligence causes of action, and sought damages for the repair of the damages and loss of the use of the project. The complaint did not allege damage to any property other than the project itself. Ewing tendered its defense to its CGL insurer Amerisure. Amerisure denied a defense and Ewing filed suit against Amerisure. The federal district trial court entered summary judgment for Amerisure. Applying Texas law, the court held that all of the damages fell within the “contractual liability†exclusion precluding any duty to defend or indemnify.
Read the full story…
Reprinted courtesy of CDCoverage.com
Illinois Court Determines Insurer Must Defend Property Damage Caused by Faulty Workmanship
July 11, 2011 — Tred R. Eyerly, Insurance Law Hawaii
The Illinois Court of Appeals determined the insurer must defend allegations of property damage arising from faulty workmanship. Milwaukee Mut. Ins. Co. v. J.P. Larsen, Inc., 2011 Ill. App. Unpub. LEXIS 1443 (Ill. Ct. App. June, 20, 2011).
Larsen was a subcontractor for Weather-Tite in a condominium building. Weather-Tite installed windows on the project and hired Larsen to apply sealant to the windows. The windows subsequently leaked and caused water damage within the complex.
The homeowner’s association sued Weather-Tite for breach of express and implied warranties. Weather-Tite filed a third-party complaint against Larsen, seeking contribution and alleging that Larsen was in breach of contract by failing to add Weather-Tite as an additional insured under Larsen’s CGL policy.
Both Weather-Tite and Larsen tendered to Larsen’s insurer. Both tenders were denied because the insurer contended the complaints alleged only construction defects, and not “property damage” or an “occurrence” within the terms of the policy.
The insurer filed suit for a declaratory judgment. The trial court granted the insurer’s motion as to Weather-Tite, but granted Larsen’s cross-motion for summary judgment.
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Former Zurich Executive to Head Willis North America Construction Insurance Group
March 1, 2012 — CDJ Staff
Insurance Journal reports that Sean McGroarty will be directing surety operations for their construction practice in North America. Previously, Mr. McGroarty was the senior vice president and head of international surety with Zurich Financial Services. He has also worked for Liberty Mutual Group and the St. Paul Companies.
Mr. McGroarty will be leading a team of professionals offering brokerage services for contract and commercial surety.
Read the full story…
Mortar Insufficient to Insure Summary Judgment in Construction Defect Case
January 6, 2012 — CDJ Staff
The US District Court of Nevada issued a summary judgment in the case of R&O Construction Company V. Rox Pro International Group, Ltd. on December 19, 2011. The case involved the installation of stone veneer at a Home Depot location (Home Depot was not involved in the case). R&O’s subcontractor, New Creation Masonry, purchased the stone veneer from Arizona Stone. Judge Larry Hicks noted that “the stone veneer failed and R&O was forced to make substantial structural repairs to the Home Depot store.”
Rox Pro asked the court for a summary judgment, which the court granted only in part. The court looked at two issues in the case, whether the installation instructions constituted a breach of implied warranty of merchantability, and whether there was a breach of an implied warranty of fitness for a particular purpose.
Judge Hicks found that there was a breach of implied warranty of merchantability. The instructions drafted by Real Stone and distributed by Arizona Stone were not sufficient for affixing the supplied stones, according to R&O’s expert, a claim the plaintiffs dispute. “Because there is an issue of material fact concerning the installation guidelines, the court shall deny Arizona Stone’s motion for a summary judgment on this issue.”
On the other hand, the judge did not find that the instructions had any bearing as to whether R&O bought the stone, since the stone was selected by the shopping center developer. This issue was, in the view of the judge, appropriately dismissed.
Read the court’s decision…
Condo Owners Worried Despite Settlement
September 13, 2012 — CDJ Staff
KB Homes may have settled a construction defect claim with Willowbrook Condominium Association, but some of the owners are still concerned about the repair process. The Sarasota, Florida Herald Tribune reports that one homeowner’s living room “ends with a white tarp.” He told the paper, “We feel like we’re not even owners of our own home.” A neighbor wondered “what happens when people get displaced while their homes are gutted?”
As part of the agreement, the condominium association will be selecting a contractor to repair the problems, while the cost will be paid by KB Homes. Nevertheless, at least one owner fears for their ability to resell his home, noting that even after repairs have been made, “do you think someone’s going to come in here and buy?”
Read the full story…
Insurer Unable to Declare its Coverage Excess In Construction Defect Case
January 6, 2012 — CDJ Staff
The Ninth Circuit Court of Appeals has upheld a summary judgment in the case of American Family Mutual Insurance Co. v. National Fire & Marine Insurance Co. Several other insurance companies were party to this case. In the earlier case, the US District Court of Appeals for Arizona had granted a summary judgment to Ohio Casualty Group and National Fire & Marine Insurance Company. At the heart of it, is a dispute over construction defect coverage.
The general contractor for Astragal Luxury Villas, GFTDC, contracted with American Family to provide it with a commercial liability policy. Coverage was issued to various subcontractors by Ohio Casualty and National Fire. These policies included blanket additional insured endorsements that provided coverage to GFTDC. The subcontractor policies had provisions making their coverage excess over other policies available to GFTDC.
The need for insurance was triggered when the Astragal Condominium Unit Owners Association filed a construction defect claim in the Arizona Superior Court. CFTDC filed a third-party claim against several subcontractors. The case was settled with American Family paying the settlement, after which it filed seeking reimbursement from the subcontractor’s insurers. The court instead granted summary judgment in favor of Ohio Casualty and National Fire.
American Family appealed to the Ninth Circuit for a review of the summary judgment, arguing that the “other insurance” clauses were “mutually repugnant and unenforceable.” The Ninth Circuit cited a case from the Arizona Court of Appeals that held that “where two policies cover the same occurrence and both contain ‘other insurance’ clauses, the excess insurance provisions are mutually repugnant and must be disregarded. Each insurer is then liable for a pro rate share of the settlement or judgment.”
The court noted that unlike other “other insurance” cases, the American Family policy “states that it provides primary CGL coverage for CFTDC and is rendered excess only if there is ‘any other primary insurance’ available to GFTDC as an additional insured.” They note that “the American Family policy purports to convert from primary to excess coverage only if CFTDC has access to other primary insurance as an additional insured.”
In comparison, the court noted that “the ‘other insurance’ language in Ohio Casualty’s additional insured endorsement cannot reasonably be read to contradict, or otherwise be inconsistent with, the ‘other primary insurance’ provision in the American Family policy.” They find other reasons why National Fire’s coverage did not supersede American Family’s. In this case, the policy is “written explicitly to apply in excess.”
Finally, the Astragal settlement did not exhaust American Family’s coverage, so they were obligated to pay out the full amount. The court upheld the summary dismissal of American Family’s claims.
Read the court’s decision…
Florida Property Bill Passes Economic Affairs Committee with Amendments
April 14, 2011 — April 14, 2011 Beverley BevenFlorez - Construction Defect Journal
The Florida Property Bill (HBB 803) was passed by the Economic Affairs Committee by a vote of 11-7, according to Property Casualty 360, after adopting nine new amendments. The additions to the bill included limiting notice of claims to a set number of years, extending the statute of limitation on property claims from five years to six years, among others.
HB 803 and SB 408, the Senate companion bill, focus primarily on residential property insurance. They make changes to the Florida Hurricane Catastrophe Fund, while also promoting increased notification of policy changes to policyholders. Sections of the bills provide minor fixes such as renaming Citizens Property Insurance Corporation to Taxpayer-Funded Property Insurance Corporation. However, other sections of the bills contain more significant policy changes such as sinkhole coverage and hurricane claims.
The bills’ intent, according to the SunSentinel.com, is to reduce fraudulent claims and to bring new insurers into the insurance market. However, SunSentinel.com also reports that the bills may drastically increase property insurance premiums.
Read the full Property Casualty 360 article...
Read the full Sun Sentinel article...
California Appeals Court Remands Fine in Late Completion Case
November 18, 2011 — CDJ Staff
The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.
The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”
Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”
Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”
The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”
The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.
The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.
Read the court’s decision…
After Katrina Came Homes that Could Withstand Isaac
October 23, 2012 — CDJ Staff
In the aftermath of Hurricane Katrina, Louisiana adopted its first uniform building code. Under the new standards, homes are better able to withstand the winds generated by hurricanes. The owner of one home said that during Hurricane Isaac, “there’s no shaking of the building itself, there’s no sign of a storm except for the rain.”
WWWLTV reports that the new standards require home to be able to withstand 130 mile per hour winds. They also must follow FEMA guidelines for elevation. Build Now, a non-profit organization, is seeking to build green homes that meet the new standards. Their executive director said “we’re building higher. We’re building stronger. We’re building greener.”
Read the full story…
Louisiana Politicians Struggle on Construction Bills, Hospital Redevelopment
June 16, 2011 — CDJ Staff
Louisiana politicians are still working on a compromise in the state’s construction budget, as reported in the Times-Picayune. Rob Marrianneax, the chair of the Senate Revenue and Fiscal Affairs Committee, removed a $45 million request from Governor Bobby Jindal and added $4 million for projects that Jindal vetoed last year.
Two senators have formed competing plans to fund redevelopment construction for New Orleans’s Methodist Hospital. Mitch Landrieu, the mayor of New Orleans, hoped for $30 million dollars in state bonds. Senator Cynthia Willard-Lewis proposed an amendment that would supply $1.6 million, while Senator J.P. Morrell has an amendment that would supply $4 million.
Read the full story…
Williams v. Athletic Field: Hugely Important Lien Case Argued Before Supreme Court
June 17, 2011 — Douglas Reiser, Builders Counsel
Well, it finally made it. The most important Washington lien case of recent memory was argued in front of the Washington Supreme Court on Tuesday, June 14, 2011. So, what should we all expect?
As I was reading through my RSS feeds this afternoon ? I was stopped dead in my tracks. Williams v . Athletic Field, the Division II case that has been a frequent topic here on Builders Counsel, has finally been argued before the Supreme Court. All of you who have been anxiously awaiting this day, you can check out the Supreme Court submissions by following this link.
The Williams case has been the center of attention for construction lawyers and construction organizations over the past year. Some have called for complete lien law reform, others have tried to patch a hole in the law. Now, we can expect a ruling from the highest court in the state. That ruling will have a major impact on whether the Legislature feels compelled to change lien law.
Read the full story…
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Hospital Construction Firm Settles Defect Claim for $1.1 Million
September 13, 2012 — CDJ Staff
Law360 reports that Bovis Lend Lease has settled claims of $10 million in damages for $1.1 million. Bovis was building three annexes to a hospital in Oklahoma. The hospital alleged that a faulty moisture barrier system lead to damage throughout the hospital.
Bovis is a division of the Lend Lease Group, a multinational construction firm based Sydney, Australia.
Read the full story…
Going Green for Lower Permit Fees
October 23, 2012 — CDJ Staff
Clay County, Kansas is offering rebates on building permits for green homes. According to the Kansas City Star, building permits in the county are typically $2,500. The county will rebate anything from half to all of the permit fee, depending on how well the builder meets green standards. The county will monitor and inspect the process to make certain that builders adhere to their promises for green construction. The county hopes this will encourage green building by offsetting the cost.
Read the full story…
California Lawyer Gives How-To on Pursuing a Construction Defect Claim
September 13, 2012 — CDJ Staff
On his recently started blog, Harry Kaladjian writes about construction defect litigation in California. He notes that after taking possession, homeowners sometimes notices problems such as “slab cracks in the garage, water leaking through the ceiling, warped floors, improper framing, cracking stucco, etc.” He goes on to note that once that happens, there are series of things homeowners must do.
The first is to be concerned about the statute of limitations. Then, “once it has been established that defects exist, the homeowner must refer to the ‘Right to Repair Act’ and ‘Calderon Procedures.’” These, he notes set out the “pre-litigation procedures prior to filing a lawsuit.”
Read the full story…
El Paso Increases Surety Bond Requirement on Contractors
April 25, 2011 — April 25, 2011 Beverley BevenFlorez - Construction Defect Journal
The city of El Paso has recently increased surety bonds required of contractors from $10,000 to $50,000, according to the El Paso Times. Proponents of the increase believe it was necessary to protect homeowners from fly-by-night builders, while opponents argue that the increase will have an adverse effect on an industry in that is already suffering due to the economic slowdown.
Arguments for and against the increase have been flooding the blogosphere with their views. Christian Dorobantescu on the Small Business Entrepreneur Blog claims that “only about 15% of the city’s 2,500 contractors had been able to secure a higher bond to remain eligible for work after the new requirements were announced.” However, insurance companies have a different take. “From a surety broker standpoint, most contractors will be able qualify for the bond; some will just have to pay higher premium rates to obtain it,” a recent post on the Surety1 blog argues.
While the increased bond may help homeowners deal with construction defect claims, it is not clear what effect it will have on builders in El Paso.
Read more from the El Paso Times…
Read more from the Small Business Entrepreneur Blog…
Read more from the Surety1 Blog…
Ghost Employees Steal Jobs from Legit Construction Firms
September 13, 2012 — CDJ Staff
Firms that skirt labor laws for construction workers can undercut firms that are obeying those laws. In a piece in Raleigh, North Carolina’s News & Observer, Doug Burton, a commercial masonry contractor summed it up: “my competitors are cheating.” The article describes the low-bidding firms “called their workers independent contractors ? or treated them like ghosts, paid under the table and never acknowledged.” The cost to the state is “unpaid medical bills for injured workers, uncollected business and personal taxes, and payments not made to a depleted state unemployment reserve.”
One firm examined in the article, Martin’s Bricklaying, employs mostly immigrant Mexican laborers, many of whom are in the country illegally. One employee told the News & Observer, “we don’t complain.”
Read the full story…
Sometimes It’s Okay to Destroy Evidence
August 17, 2011 — CDJ Staff
The Minnesota Supreme Court has ruled in the case of Miller v. Lankow that Mr. Miller was within his rights to remediate his home, even though doing so destroyed the evidence of water intrusion.
Linda Lankow built a home in 1992. In 2001 or 2002, Lankow discovered a stucco problem at the garage which she attributed to moisture intrusion. She asked the original contractor to fix the wall. In 2003, Lankow attempted to sell her home, but the home inspection revealed fungal growth in the basement. Lankow made further repairs, including alterations to the landscaping.
In 2004, Lankow put her house on the market once again and entered into an agreement with David Miller. Miller declined to have an independent inspection, as the home had been repaired by professional contractors.
In 2005, Miller put the house on the market. A prospective buyer requested a moisture inspection. The inspection firm, Private Eye, Inc. found “significant moisture intrusion problems.”
Miller hired an attorney who sent letters to the contractors and to Lankow and her husband. Lankow’s husband, Jim Betz, an attorney, represented his wife and sent a letter to Miller’s attorney that Miller had declined an opportunity to inspect the home.
In 2007, Miller’s new attorney sent letters to all parties that Miller had decided to begin remediation work on the house. All stucco was removed. Miller then filed a lawsuit against the prior owners, the builders, and the realtors.
Two of the contractors and the prior owners moved for summary judgment on the grounds that Miller had spoliated evidence by removing the stucco. They requested that Miller’s expert reports be excluded. The district court found for the defendants and imposed sanctions on Miller.
The Minnesota Supreme court found that “a custodial party’s duty to preserve evidence is not boundless,” stating that “it may be particularly import to allow remediation in cases such as the one before us.” Their reasoning was that “remediation of the moisture intrusion problem in the home may be necessary, even essential, to address immediate health concerns.”
Given that Miller needed to remediate the problem in order to continue living there, and that he had given the other parties a “full and fair opportunity to inspect,” the court found that he was within his rights. The court reversed the judgment of the lower court and remanded it to them for review.
Read the court’s decision…
