Analysis of the “owned property exclusion” under Panico v. State Farm
March 8, 2011 — March 8, 2011, Colorado Construction Litigation
The U.S. Court of Appeals for the Tenth Circuit recently concluded that the “owned property exclusion” applied to bar coverage for claims of property damage. See Panico v. State Farm Fire and Cas. Co., 2011 WL 322830 (10th Cir. 2011). In Panico, the plaintiffs sold property in Aspen, Colorado to the Taylors, who sued the Panicos upon discovering the property was not as represented. After refusing to defend, the Panicos sued State Farm for breach of contract. The district court concluded that the Taylors’ claims were not covered under the Panicos insurance policies and granted summary judgment in State Farm’s favor. The U.S. Court of Appeals for the Tenth Circuit affirmed.
Mr. Panico built the house on the property as well as several additions to the house. As the Taylors lived in Florida, they primarily relied on their real estate agent and an inspector to ensure the property was acceptable. According to their complaint, the Taylors discovered that the house was “virtually uninhabitable due to serious design and construction defects, mold, rodents, and drainage problems.” Id. at *1. In their complaint, the Taylors asserted three claims for relief against the Panicos based upon misrepresentation and fraudulent concealment about the condition of the property.
Read the full story...
Reprinted courtesy of Heather M. Anderson of Higgins, Hopkins, McClain & Roswell, LLP. Ms Anderson can be contacted at anderson@hhmrlaw.com
Nevada Senate Rejects Construction Defect Bill
June 7, 2011 — CDJ Staff
The Las Vegas Sun reports that Assembly Bill 401, the construction defect bill, lost in a vote of 9 to 12. The measure extended the time for construction defect suits to be filed, awarded legal costs only to successful plaintiffs, and set a definition of construction defects. Two Democrats joined the Republicans in the Senate in defeating the bill.
Read the full story…
Businesspeople to Nevada: Revoke the Construction Defect Laws
March 1, 2012 — CDJ Staff
The Nevada chapter of the National Federation of Independent Businesses has said that Nevada’s construction defect and minimum wage laws are hampering job growth. The organization conducted a survey, and although only about two percent of the members responded, they passed the opinions of the group on to Governor Brian Sandoval. Sandoval has said, according to the report by Fox News Reno, that he wants the state to be more business friendly. He supports reforms to Nevada’s construction defect laws, saying that he’d “like to see some reform” on the issue of mandatory attorney’s fees.
Randi Thompson, the spokesperson for the Nevada chapter of the National Federation of Independent Businesses, said that members of her organization would like to see current Nevada construction defect law revoked. She described current law as “driven towards lawyers and not toward protecting consumers.”
Read the full story…
General Contractor/Developer May Not Rely on the Homeowner Protection Act to Avoid a Waiver of Consequential Damages in an AIA Contract
August 4, 2011 — Higgins, Hopkins, McLain & Roswell, LLC
Recently, in Caribou Ridge Homes, LLC v. Zero Energy, LLC, et al., Case No. 10CV1094, Boulder County District Court Judge Ingrid S. Bakke entered a ruling and order on the Plaintiff’s Motion for Determination of Question of Law Pursuant to C.R.C.P. 56(h) on Issue of Damages. The Order found that the Plaintiff was not a homeowner intended to be protected by the Homeowner Protection Act (the “HPA”) and thus could not pursue its claims for consequential damages against Defendant.
By way of background, on June 18, 2008, Plaintiff Caribou Ridge Homes, LLC (“Caribou”) entered into a Standard Form Agreement Between Owner and Contractor AIA Document A114-2001 (the “Contract”) with Defendant Zero Energy, LLC (“Zero Energy”). Plaintiff hired Zero Energy to serve as a general contractor for the construction of a single-family home in the Caribou Ridge subdivision in Nederland, Colorado. A provision in the contract contained a mutual waiver of consequential damages (“Waiver”).
Read the full story…
Reprinted courtesy Higgins, Hopkins, McLain & Roswell, LLC
BHA Expands Construction Experts Group
October 28, 2011 — Bert L. Howe & Associates, Inc. - Corporate Offices
Bert L. Howe & Associates, Inc., one of the nation’s leading construction forensics firms is pleased to announce the expansion of the company’s civil and structural engineering capabilities.
JERRY M. MILES, PE - Mr. Miles has been a licensed civil engineer in California since 1987 and has served as the lead civil engineer on many projects in several states. His experience includes contract administration services as the owner’s representative on a variety of projects including mastered planned communities, residential subdivisions, shopping centers and multi-family residential projects. He has also been involved in providing water quality management plans and storm water pollution prevention plans. Mr. Miles has also served on the Town of Apple Valley’s Building Department Dispute Resolution Board.
His more than 26 years of engineering experience includes geotechnical evaluations, structural design of wood-framed, masonry, and concrete tilt-up buildings, small and large subdivision engineering construction/improvements plans, hydrology/hydraulic reports and design, forensic investigation and expert witness testimony. Mr. Miles has qualified as an expert in numerous jurisdictions and Federal court. He has been called upon to provide deposition testimony on more than twenty-five occasions and has successfully testified at arbitration and trial. Click here to view Mr. Miles’ Current CV.
MATTHEW J. STIEFEL, PE - With a background that spans a multitude of design and new construction projects to catastrophic claims analysis, Mr. Stiefel brings a unique set of credentials and experience to the construction experts group at Bert L. Howe & Associates. Mr. Stiefel has more than 13 years’ experience in civil, structural, and geotechnical engineering; providing design and construction consulting services on a variety of projects that include multi-family and single family dwellings, commercial buildings, transportation facilities, industrial facilities, storm drain channels, water and wastewater pipelines. His engineering experience encompasses multiple disciplines of civil engineering including geotechnical design and evaluation, foundation design, structural design of wood-framed buildings, preparation of grading plans and site drainage analysis. He has provided cause and origin analysis for insurance adjusters on many residential and commercial sites related to issues involving moisture intrusion and mold, foundation movement, site drainage, soil movement, wind damage, and other various losses. Click here to view Mr. Stiefel’s Current CV.
Will They Blow It Up?
March 28, 2012 — CDJ Staff
The issues concerning the Harmon Towers building in Las Vegas continue to make their way through the courts. As we noted in a previous piece, Cook County building officials stated that the building could be a hazard if Las Vegas were struck by an earthquake. The question of whether the building will continue to stand is just one of the issues in front of a judge.
MGM Resorts International argued at a March 13 hearing for permission to implode the Harmon hotel building. They claim that more than 1,700 defects have been discovered in the building and that the building is a public safety hazard. Arguing against demolition, Perini Building Company, the general contractor for the hotel, and its subcontractors are claiming that imploding the building would destroy evidence and prejudice juries in the ongoing construction defect claims. They claim that MGM Resorts wishes to abandon the building due to the economic slowdown. Perini Corp, the contractor for the project, claims that the building can be fixed. Perini claims that MGM’s position in the construction trial would be improved if the building is demolished.
After Judge Elizabeth Gonzalez heard the four days of testimony on the Harmon Towers building and whether it should be demolished, she scheduled more testimony, with two days in April and an entire week in July. Judge Gonzalez will be deciding whether the building will be torn down, imploded, or left in place.
Read the full story…
Read the full story…
Texas exclusions j(5) and j(6).
April 27, 2011 — April 27, 2011, by CDCoverage.com
In Evanston Ins. Co. v. D&L Masonry of Lubbock, Inc., No. 07-10-00358-CV (Tex. Ct. App. April 18, 2011), insured masonry subcontractor D&L sued its CGL insurer Evanston to recover costs incurred by D&L for the replacement of window frames damaged by D&L while performing masonry work adjacent to the window frames. The trial court granted summary judgment for D&L.
Read the full story…
Reprinted courtesy of CDCoverage.com
School District Settles Construction Lawsuit
November 7, 2012 — CDJ Staff
The Franklin County, Pennsylvania Public Opinion reports that an area school is coming to an end with its construction lawsuit. The school district was sued by its contractors for a combined $1.4 million, which the school district withheld when the project was not completed on schedule. Lobar Inc. claimed that the district additionally owed interest and should pay attorney fees. The school claimed that only $1.15 million was due under the contract. Under the settlement, they will be paying $1.136 million.
Read the full story…
Green Buildings Could Lead to Liabilities
March 28, 2012 — CDJ Staff
Attempts to build “green,” reducing energy costs and increasing the use of sustainable building materials, may lead to more lawsuits, according to a report issued by the British Columbia Construction Association. The report warned those who were going to build green look into the implications. The report looked at the result of green building practices and requirements adopted in the United States.
The report warns that “the use of novel, less harmful building material or new construction techniques may give rise to liability due to: contractor inexperience with installation; lack of long-term evaluation of green materials; lack of understanding of how new building materials may impact existing traditional building systems; or warranties provided unintentionally about the durability or effectiveness of unproven materials or techniques.”
Manley McLachlan, president of the BCAA noted that they are aware of “legal action around the performance of the buildings,” noting that while fast-growing trees help toward LEED certification, their wood is more prone to mold. He also felt that low-VOC paints needed more testing to prove their durability as exterior finishes.
Read the full story…
Australian Group Seeks Stronger Codes to Combat Dangerous Defects
October 23, 2012 — CDJ Staff
The Owners Corporation Network, a group that represents condominium owners in Australia, has raised concerns about building defects in high-rise building that can lead to safety problems. The group prepared a statement which would strengthen the rights of owners, but the government official, Fair Trading Minister Anthony Roberts, declined to sign it. A spokesperson for the group cited a fatal fire at a Sydney high rise, noting that “there had been issues of certification which has been a concern of the Owners Corporation Network.” The Australian Broadcasting Network reports that the government will be reviewing the laws concerning high-rise apartment buildings.
Read the full story…
California Appeals Court Remands Fine in Late Completion Case
November 18, 2011 — CDJ Staff
The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.
The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”
Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”
Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”
The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”
The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.
The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.
Read the court’s decision…
A Call to Washington: Online Permitting Saves Money and the Environment
October 28, 2011 — Douglas Reiser, Builders Counsel
Here’s some good news for Oregon contractors: Electronic Permitting is here. That’s right, no more standing in line with folders full of printed submittals and waiting all day for your permit. The click of a few buttons and you are in business. Great news, right? Unfortunately, Oregon isn’t sharing that celebration with Washington. So I say - why not?
Last week, the State of Oregon released its new ePermitting online interface. The website allows contractors, owners and even local building departments to create an account, submit building plans and procure permits. With your account, you can track the progress of submissions, print documents and get posting information.
The state ran a limited test version in the City of Florence since 2009, working out the kinks. Perhaps the most impressive result of the new system is that Oregon tackled the task of coagulating a local process into one central location.
Read the full story...
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Harmon Hotel Construction Defect Update
July 18, 2011 — CDJ Staff
Coverage of the ongoing litigation concerning the Harmon Hotel continues to proliferate. Architectural Record and a number of other news outlets continue to provide additional details and coverage of the matter. Chief among the conditions alleged are improperly installed reinforcing steel inside link beams on 15 floors. MGM Claims that the conditions amount to hundreds of millions of dollars in damages, while Perini (the builder) indicated in a July 12th statement that the buildings problems are related to the design, and the they are “fixable.”
There is significant speculation that MGM Resorts International isn’t interested in repairing the hotel due to a glut of hotel rooms attendant to the troubled economy. In a statement Tuesday Perini reportedly stated that “Repairing and opening the Harmon would only create a greater glut of unused hotel rooms for MGM,” “If market conditions were better and MGM found that demand existed for the Harmon hotel rooms, MGM would not be claiming that the Harmon is unstable.”
MGM asserts that Perini failed to ”properly construct” the project. Clark County’s Department of Development Services has reportedly asked MGM to provide a plan to fix the project by August 15th.
The Harmon is part of the $8.5 billion CityCenter project that opened in the fourth quarter of 2009 and is jointly owned by MGM Resorts and Dubai World.
Prior reports indicated that the owner (MGM) had considered razing the entire project. The future of the project remains uncertain.
Judge Okays Harmon Tower Demolition, Also Calls for More Testing
August 2, 2012 — CDJ Staff
Vegas.Inc reports that Clark County District Court Judge Elizabeth Gonzalez has permitted the demolition the tower, which MGM Resorts has claimed is a safety hazard. Perini Building Co. claims that the building does not need to be demolished. CityCenter claims that repairing the building would take nearly a year longer than a demolition and cost about $200 million. Further, CityCenter assumes that the building’s reputation would cost it another $30 million.
Subsequently, Judge Gonzalez ruled that the pattern of destructive testing would not support a claim that there were an estimated 1,400 defective items in the building. An attorney for CityCenter, Steve Morris, has suggested that they may seek more testing, impossible to do once the building is demolished. CityCenter issued a statement that “nearly every time CityCenter has chipped away concrete to review structural work at the Harmon, we have found defects.” They describe the building as “unusable.”
Tutor Perini contends that it “remains confident that it will prevail when the issues of safety, reparability and responsibility for the issues facing the Harmon tower are considered.
Read the full story…
Colorado Court of Appeals Rejects Retroactive Application of C.R.S. § 13-20-808.
April 25, 2012 — Chad W. Johnson, Higgins, Hopkins, McClain & Roswell, LLC
In TCD, Inc. v. American Family Mutual Insurance Company, TCD appealed the district court’s summary judgment ruling in favor of American Family. TCD, Inc. v. American Family Mutual Insurance Company Colo. App. No. 11CA1046 (April 12, 2012). TCD was the general contractor on a project to construct a building for Frisco General Gateway Center, LLC (“Gateway”). TCD subcontracted with a roofer named Petra Roofing and Remodeling Company (“Petra”) to performing the roofing work for the building. The subcontract required Petra to defend and indemnify TCD and to name TCD as an additional insured under its CGL policy. American Family issued a CGL policy to Petra that named TCD as an additional insured from 2006-2007.
TCD filed suit against Gateway seeking payment for its work at the project. Gateway counterclaimed against TCD for breach of contract, negligence, and violation of the CCPA. TCD demanded that American Family defend it from the counterclaims pursuant to Petra’s policies. American Family denied coverage and a separate coverage suit ensued. At the trial court level, the court entered summary judgment for American Family because the counterclaims of Gateway did not trigger the duty to defend or indemnify TCD as an additional insured.
On appeal, TCD argued that: 1) the counterclaims raise a genuine issue of material fact regarding American Family’s duty to defend; 2) the court should hear evidence beyond the four corners of the complaint; and, 3) the court should apply C.R.S. § 13-20-808 retroactively.
Read the full story… Reprinted courtesy of Chad W. Johnson of Higgins, Hopkins, McClain & Roswell, LLC. Mr. Johnson can be contacted at johnson@hhmrlaw.com.
Certificate of Merit to Sue Architects or Engineers Bill Proposed
May 3, 2011 — May 3, 2011 Beverley BevenFlorez - Construction Defect Journal
North Carolina may become the twelfth state to require a Certificate of Merit to sue an architect or engineer. If North Carolina Senate Bill 435 (SB435) passes, then plaintiffs when filing a complaint will need to also attach an affidavit of a third-party licensed professional engineer or architect stating that the case has merit.
SB435 is a short two pages in its current form. The bill states that the “third-party licensed professional engineer or licensed architect shall (i) be competent to testify and hold the same professional license and practice in the same area of practice as the defendant design professional and (ii) offer testimony based upon knowledge, skill, experience, education, training, and practice. The affidavit shall specifically state for each theory of recovery for which damages are sought, the negligence, if any, or other action, error, or omission of the design professional in providing the professional service, including any error or omission in providing advice, judgment, opinion, or a similar professional skill claimed to exist and the factual basis for each such claim. The third-party licensed professional engineer or licensed architect shall be licensed in this State and actively engaged in the practice of engineering or architecture respectively.”
A few of the amendments allude to disciplining design professionals who certify civil actions that are without merit. The bill has been referred to the Committee on Judiciary I.
While North Carolina is considering enacting a Certificate of Merit law, eleven other states already require one, including Arizona, California, Colorado, Georgia, Maryland, Minnesota, New Jersey, Oregon, Pennsylvania, South Carolina, and Texas. Christopher D. Montez, a partner with Thomas, Feldman & Wilshusen, LLP, has written a useful summary for each state’s certificate of merit scheme.
Read the text of SB435
Track the progress of SB435
Read more from Christopher D. Montez’s article on Thomas, Feldman & Wilshusen, LLP site
Cogently Written Opinion Finds Coverage for Loss Caused By Defective Concrete
November 7, 2012 — Tred Eyerly, Insurance Law Hawaii
If ever in need of a concise, well-reasoned opinion on “occurrence,” “property damage” and applicability of the business risk exclusions, turn to Pamperin Rentals II, LLC v. R.G. Hendricks & Sons Construction, Inc., 2012 Wis Ct. App. LEXIS 698 (Wis. Ct. App. Sept. 5, 2012).
A contractor was hired to install concrete during construction of seven gas stations. Red-D-Mix provided the concrete. The contractor and Red-D-Mix were eventually sued by the gas stations, based upon allegations that the concrete was defectively manufactured and installed. The gas stations alleged that Red-D-Mix supplied concrete that was defective and resulted in damages, including the need to repair nearby asphalt.
Red-D-Mix tendered to its insurers, who denied coverage. Suit was filed and the insurers moved for summary judgment. The trial court determined there were no allegations of either “property damage” or an “occurrence.” Therefore, there was no duty to defend or indemnify Red-D-Mix.
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Faulty Workmanship may be an Occurrence in Indiana CGL Policies
April 7, 2011 — April 7, 2011 Beverley BevenFlorez - Construction Defect Journal
The question of whether construction defects can be an occurrence in Commercial General Liabilities (CGL) policies continues to find mixed answers. The United States District Court in Indiana denied the Plaintiff’s Motion for Summary Judgment in the case of General Casualty Insurance v. Compton Construction Co., Inc. and Mary Ann Zubak stating that faulty workmanship can be an occurrence in CGL policies.
Judge Theresa L. Springmann cited Sheehan Construction Co., et al. v. Continental Casualty Co., et al. for her decision, ”The Indiana Supreme Court reversed summary judgment, which had been granted in favor of the insurer in Sheehan, holding that faulty workmanship can constitute an ‘accident’ under a CGL policy, which means any damage would have been caused by an ‘occurrence’ triggering the insurance policy’s coverage provisions. The Indiana Supreme Court also held that, under identically-worded policy exclusion terms that are at issue in this case, defective subcontractor work could provide the basis for a claim under a CGL policy.”
As we reported on April 1st, South Carolina’s legislature is currently working on bill S-431 that would change the wording of CGL policies in their state to include construction defects. Ray Farmer, Southwest region vice president of the American Insurance Association spoke out against the bill. “CGL policies were never meant to cover faulty workmanship by the contractor,” he said. “The bill’s supplementary and erroneous liability provisions will only serve to unnecessarily impact construction costs in South Carolina.”
Read the Opinion and order...
Read the court’s ruling...
Read the American Insurance Association statement...
